Personal Info

Username (Email)
First Name
Last Name 

Additional info

 
Phone

I agree with terms & conditions   

SOFTWARE LICENSE AGREEMENT This Software License Agreement ("Agreement") is made and effective the date of enrollment by and between Strong Family Fund, Inc. ("Developer") and [the Distributor] ("Licensee"). Developer has developed and licenses to users its software programs marketed under the names $60 Explosion, 4StepLoanMod, 4StepDebtMod, CreditRepairAce, BOSS© Review, Millionaire Profits Success Center, Solutions Software Matrix Control Panel, and all variations of the aforementioned (the "Software"). Licensee desires to utilize the Software. NOW, THEREFORE, in consideration of the mutual promises set forth herein, Developer and Licensee agree as follows: 1. License. Developer hereby grants to Licensee a perpetual, non-exclusive, limited license to use the Software in the United States of America as set forth in this Agreement. 2. Restrictions. Licensee shall not modify, copy, rebrand, re-label, duplicate, reproduce, license or sublicense the Software, or transfer or convey the Software or any right in the Software to anyone else without the prior written consent of Developer. 3. Fee. In consideration for the grant of the license and the use of the Software, Licensee agrees to pay Developer the sum of license fee. Actual Licensee fee amount will vary depending on the Licensee-Level selected by Licensee. Licensee-Level fee amounts will be published from time to time by Developer. 4. Warranty of Title. Developer hereby represents and warrants to Licensee that Developer is the owner of the Software or otherwise has the right to grant to Licensee the rights set forth in this Agreement. In the event any breach or threatened breach of the foregoing representation and warranty, Licensee's sole remedy shall be to require Developer or to either: i) procure, at Developer's expense, the right to use the Software, ii) replace the Software or any part thereof that is in breach and replace it with Software of comparable functionality that does not cause any breach, or iii) refund to Licensee the full amount of the license fee upon the return of the Software and all copies thereof to Developer. 5. Warranty of Functionality. A. For a period of 60 days following delivery of the Software to Licensee (the "Warranty Period"), Developer warrants that the Software shall perform in all material respects according to the Developer's specifications concerning the Software when used with the appropriate computer equipment. In the event of any breach or alleged breach of this warranty, Licensee shall promptly notify Developer and return the Software to Developer at Licensee’s expense. Licensee’s sole remedy shall be that Developer shall correct the Software so that it operates according to the warranty. This warranty shall not apply to the Software if modified by anyone or if used improperly or on an operating environment not approved by Licensor. B. In the event of any defect in the media upon which the Software is provided arising within 60 days of the date of delivery of the Software, upon return to Developer of the Software upon the original media, Developer shall provide Licensee a new copy of the Software. C. DUE TO PROPRIETARY NATURE OF MOST MATERIAL SOLD, ALL SALES ARE FINAL, UNLESS OTHERWISE SPECIFICALLY OFFERED IN WRITING. IF APPLICABLE, RETURNS ARE SUBJECT TO A 15% RESTOCKING AND MERCHANT PROCESSING FEE AND DO NOT INCLUDE SHIPPING PAID. THIS AGREEMENT IS NOT CANCELABLE FOR ANY REASON AFTER 72 HOURS OF DELIVERING INITIAL PROPRIETARY TRAINING MATERIALS AND/OR SOFTWARE BY EMAIL. 6. Software Maintenance. A. Standard maintenance. During the Warranty Period, Developer shall provide to Licensee any new, corrected or enhanced version of the Software as created by Developer. Such enhancement shall include all modifications to the Software which increase the speed, efficiency or ease of use of the Software, or add additional capabilities or functionality to the Software, but shall not include any substantially new or rewritten version of the Software. B. Optional maintenance. After expiration of the Warranty Period, Licensee may continue to receive maintenance support for successive twelve (12) month periods. The charge for such optional maintenance support shall be Developer's regular list price for maintenance and support for the Software as published from time to time by Developer. Licensor shall notify Developer in writing if it desires to receive optional maintenance. If Licensee fails to take optional maintenance and later elects to receive it, Developer reserves the right to charge Licensee its maintenance fees for the period of the lapse in maintenance. Developer may elect to discontinue maintenance at any time upon notice to Licensee, and refund of any then unearned maintenance fees. 7. Payment. Payment of the license fee shall be made at the time Licensee enrolls in the Distribution Program. Delivery of the Licensee-Level Software will be available immediately after enrollment. Some Licensee-Level Software will be delivered within 5 business days (after Licensee has provided all required information) of enrollment due to potential customization requirements. Payment of any other amount owed by Licensee to Developer pursuant to this Agreement shall be paid within thirty (30) days following invoice from Developer. In the event any overdue amount owed by Licensee is not paid following ten (10) days written notice from Developer, then in addition to any other amount due, Developer may impose and Licensee shall pay a late payment charge at the rate of one percent (1%) per month on any overdue amount. 8. Taxes. In addition to all other amounts due hereunder, Licensee shall also pay to Developer, or reimburse Developer as appropriate, all amounts due for property tax on the Software and for sales, use, excise taxes or other taxes which are measured directly by payments made by Licensee to Developer. In no event shall Licensee be obligated to pay any tax paid on the income of Developer or paid for Developer's privilege of doing business. 9. Warranty Disclaimer. DEVELOPER'S WARRANTIES SET FORTH IN THIS AGREEMENT ARE EXCLUSIVE AND ARE IN LIEU OF ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO, THE IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. 10. Limitation of Liability. Developer shall not be responsible for, and shall not pay, any amount of incidental, consequential or other indirect damages, whether based on lost revenue or otherwise, regardless of whether Developer was advised of the possibility of such losses in advance. In no event shall Developer's liability hereunder exceed the amount of license fees paid by Licensee, regardless of whether Licensee's claim is based on contract, tort, strict liability, product liability or otherwise. 11. Notice. Any notice required by this Agreement or given in connection with it, shall be in writing and shall be given to the appropriate party by personal delivery or by certified mail, postage prepaid, or recognized overnight delivery services. If to Developer: Strong Family Fund, Inc. 9856 Ashburn Lake Drive Tampa, FL 33610 If to Licensee: Licensee’s Name on Record in Distributor Tracking System Licensee’s Address on Record in Distributor Tracking System 12. Governing Law. This Agreement shall be construed and enforced in accordance with the laws of the state of Florida. 13. No Assignment. Neither this Agreement nor any interest in this Agreement may be assigned by Licensee without the prior express written approval of Developer. 14. Final Agreement. This Agreement terminates and supersedes all prior understandings or agreements on the subject matter hereof. This Agreement may be modified only by a further writing that is duly executed by both parties. 15. Severability. If any term of this Agreement is held by a court of competent jurisdiction to be invalid or unenforceable, then this Agreement, including all of the remaining terms, will remain in full force and effect as if such invalid or unenforceable term had never been included. 16. Headings. Headings used in this Agreement are provided for convenience only and shall not be used to construe meaning or intent. 17. Dispute Resolution In the event any dispute or controversy arising out of or relating to this Agreement, the parties agree to exercise their best efforts to resolve the dispute as soon as possible. The parties shall, without delay, continue to perform their respective obligations under this Agreement which are not affected by the dispute. {Include all that apply; delete those that do not:} Mediation. In the event that the parties can not by exercise of their best efforts resolve the dispute, they shall submit the dispute to Mediation. The parties shall, without delay, continue to perform their respective obligations under this Agreement which are not affected by the dispute. The invoking party shall give to the other party written notice of its decision to do so, including a description of the issues subject to the dispute and a proposed resolution thereof. Designated representatives of both parties shall attempt to resolve the dispute within [time period] after such notice. If those designated representatives cannot resolve the dispute, the parties shall meet at a mutually agreeable location and describe the dispute and their respective proposals for resolution to responsible executives of the disputing parties, who shall act in good faith to resolve the dispute. If the dispute is not resolved within [time period] after such meeting, the dispute shall be submitted to binding arbitration in accordance with the Arbitration provision of this Agreement. Arbitration. Any controversies or disputes arising out of or relating to this Agreement shall be resolved by binding arbitration in accordance with the then current Commercial Arbitration Rules of the American Arbitration Association. The parties shall endeavor to select a mutually acceptable arbitrator knowledgeable about issues relating to the subject matter of this Agreement. In the event the parties are unable to agree to such a selection, each party will select an arbitrator and the arbitrators in turn shall select a third arbitrator. The arbitration shall take place at a location that is reasonably centrally located between the parties, or otherwise mutually agreed upon by the parties. All documents, materials, and information in the possession of each party that are in any way relevant to the claim(s) or dispute(s) shall be made available to the other party for review and copying no later than [time period] after the notice of arbitration is served. The arbitrator(s) shall not have the authority, power, or right to alter, change, amend, modify, add, or subtract from any provision of this Agreement or to award punitive damages. The arbitrator shall have the power to issue mandatory orders and restraining orders in connection with the arbitration. The award rendered by the arbitrator shall be final and binding on the parties, and judgment may be entered thereon in any court having jurisdiction. The agreement to arbitration shall be specifically enforceable under prevailing arbitration law. During the continuance of any arbitration proceeding, the parties shall continue to perform their respective obligations under this Agreement. 18. Force Majeure Neither party shall be liable in damages or have the right to terminate this Agreement for any delay or default in performing hereunder if such delay or default is caused by conditions beyond its control including, but not limited to Acts of God, Government restrictions (including the denial or cancellation of any export or other necessary license), wars, insurrections and/or any other cause beyond the reasonable control of the party whose performance is affected. 19. $60 Explosion Rebate SFF, Inc. is not responsible for the rebate payment. All licensees agree that they will complete this payment in good faith to all qualified new licensees. All licensees agree to hold SFF, Inc. harmless in all disputes over rebate payments. 20. Amendment No modification or claimed waiver of any provision of this Agreement shall be valid except by written amendment signed by authorized representatives of Licensor and Licensee. 21. Waiver of Contractual Right Waiver of any provision herein shall not be deemed a waiver of any other provision herein, nor shall waiver of any breach of this Agreement be construed as a continuing waiver of other breaches of the same or other provisions of this Agreement. 22. Acceptance and Agreement BY USING THIS Software AND THE ASSOCIATED FILES AND WRITTEN MATERIALS (the "Documentation"), YOU AGREE THAT ALL OF THE TERMS AND CONDITIONS ABOVE APPLY TO YOU AND ANYONE ELSE WHO USES THIS SOFTWARE, IF EITHER: * PUT A CHECK IN A BOX INDICATING THAT YOU AGREE WITH THE TERMS AND CONDITIONS OF THIS AGREEMENT, OR * YOU COPY, INSTALL, OR USE THIS SOFTWARE, OR * YOU PERMIT OR ENABLE OTHERS TO COPY, INSTALL OR USE THIS SOFTWARE. IF YOU DO NOT AGREE, PLEASE TERMINATE DOWNLOAD AND INSTALLATION IMMEDIATELY; YOU MAY NOT USE THIS SOFTWARE OR BECOME A LICENSEE.